Tenders Are Invited For Tauranga Moana Courthouse Project - Main Contractor

Registration Of Interest (Roi) For Tauranga Moana Courthouse Project - Main Contractor. Open Date: Monday, 14 August 2023 9:00 Am (Pacific/Auckland Utc+12:00) Close Date: Friday, 1 September 2023 5:00 Pm (Pacific/Auckland Utc+12:00) Tender Type: Registration Of Interest (Roi) Tender Coverage: Sole Agency Regions: Bay Of Plenty Required Pre-Qualifications: None Overview: In Partnership With Te Khui Hap O Te Papa, The Ministry Of Justice Releases An Open Registration Of Interest (Roi) Calling For Suitably Qualified, Experienced, And Resourced Main Contractor (Or A Consortium, With One Lead Main Contractor) Who Are Interested In The Opportunity To Be Engaged By The Ministry Of Justice (Ministry, Or Buyer) As The Preconstruction Contractor (Construction Consultant) For The Tauranga Moana Courthouse Project (Project). The Project Comprises: The Construction Of The New Tauranga Courthouse (Courthouse Project); And The Refurbishment Of Mclean House (Refurbishment Project). From Roi Submissions, Up To Four Respondents Will Be Short-Listed And Invited To Submit A Tender Through A Subsequent Request For Tender (Rft). The Successful Respondent Will Be Engaged By The Ministry As The Construction Consultant Under A Pre-Construction Services Agreement (Pcsa) To Provide Preconstruction Services In Relation To Both The Courthouse And Refurbishment. All Enquiries Must Be Submitted Through Gets. Tender Link : Https://Www.Gets.Govt.Nz/Moj/Externaltenderdetails.Htm?Id=27873305