Tenders Are Invited For The Replacement Of Kitchen Catering Equipment At Broadway Infants And Crossways Junior School, South Gloucestershire

The Project Requirement Over The Summer 2023 Period Is To Replace The Existing Gas Kitchen Catering Equipment With New Electric Models With Associated Electrical And Building Works At Broadway Infants School, Yate And Crossways Junior School, Thornbury.This Work Is Being Undertaken As Part Of The Council’S 2023/24 Schools Capital Repair And Maintenance Programme.The Council Is Seeking A Gas Safetm/ Niceic Approved Electrical Contractor To Act As Principal Contractor With The Capability And Experience For School Kitchen And Catering Works. The Council Will Not Consent To The Whole Of The Works To Be Sub-Contracted. It Is Essential That This Project Is Successfully Executed During The Summer Recess, So The Contractor Will Need To Demonstrate They Have Recently Completed At Least One Similar Project Successfully (Similar Scope Of Work, Similar Value And Similar Timescale) And They Have The Competency And Sufficient Resources To Meet These Deadlines.The Contractor Shall Appoint A Site-Based Supervisor Throughout The Works On Site. It Is Expected The Contractor Will Have To Work Longer Weekdays And Weekends During The School Holiday Period (22Nd July To 31St August 2023) To Complete The Work Within The Contract Programme Requirements And Include These Costs In Their Tender.The Works Shall Be Carried Out In Accordance With The Construction (Design And Management) Regulations 2015. The Contractors Will Need To Demonstrate They Are Fully Conversant With Their Responsibilities Under The Regulations In Their Tender Return And Allow For All Costs Associated With Their Management Of The Contract.The Whole Of The Works Are To Be Carried Out In Accordance With The Terms And Conditions Of The Jct Minor Works Building Contract 2016, Published On Behalf Of The Joint Contracts Tribunal Limited By Thomson Reuters (Legal) Limited Trading As Sweet & Maxwell. The Contractor Shall Obtain A Copy Of The Joint Contracts Tribunal Limited Minor Works Building Contract 2016 And Shall Make Themselves Aware Of The Conditions Therein.