Tenders Are Invited For Development Of The Interior Of The Courtyard At The Building Of The Housing Community Of Waryńskiego 45C In Gdańsk.

1. The Subject Of The Order Is The Development Of The Interior Of The Courtyard At The Building Of The Housing Community Of Waryńskiego 45C In Gdańsk.2.The Scope Of Works Includes: - Carrying Out Preparatory And Demolition Works, - Repairing The Existing Hardening, - Making A Paving Stone Surface, - Carrying Out Earthworks, - Delivery And Installation Of Park Deckchairs, - Delivery And Installation Of Bicycle Racks, - Delivery And Installation Of Lighting Posts, - Planting Shrubs, - Execution Planting Trees,  Planting Flower Beds,  Carrying Out Manual Sowing Of Grass,  Supervising The Greenery Inspector, A Detailed Description Of The Subject Of The Order Includes: 1) Area Development Design. Reconstruction, Landscaping Of The Existing Yard And Construction Of Small Architectural Structures And Bicycle Racks Between Ul. Konopnicka And Ul. Waryńskiego In Gdańsk - Annex 5 To Swz, 2) Greenery Protection Project. Reconstruction, Landscaping Of The Existing Yard And Construction Of Small Architecture Objects In The Form Of A Garden Pergola, Benches, Flower Pots And Bicycle Racks Between Ul. Konopnicka And Ul. Waryńskiego In Gdańsk - Annex 6 To Swz,3) Detailed Technical Specification For The Execution And Acceptance Of Construction Works - Annex 7 To Swz4) Bill Of Quantities. Reconstruction, Landscaping Of The Existing Yard And Construction Of Small Architectural Structures And Bicycle Racks Between Ul. Konopnicka And Ul. Waryńskiego In Gdańsk - Annex 8 To The Swz, 5) Standard Of Protection Of Trees And Other Forms Of Greenery In The Investment Process - Annex 9 To The Swz. Pursuant To Art. 649 Cc In Case Of Doubt, The Contractor Is Deemed To Have Undertaken All The Works Covered By The Designs And The Technical Specification For The Execution And Acceptance Of Works Constituting Part Of The Contract. In Such A Case, The Determinants Of The Scope Of Construction Works To Be Performed By The Contractor Are The Designs, Detailed Technical Specifications For The Execution And Acceptance Of The Works.