Tenders Are Invited For Improving The Thermal Insulation Of The Ceiling And The Safety Of Access To The Roof In The Building Of The Court Of Appeal In Rzeszów

1.Przedmiotem Zamówienia Są Roboty Budowlane W Ramach Zadania Pn. Improvement Of The Thermal Insulation Of The Ceiling And The Safety Of Access To The Roof In The Building Of The Court Of Appeal In Rzeszów. The Scope Of The Contract Includes In Particular The Following Tasks: Dismantling And Disposal Of Ineffective Ceiling Insulation. Disassembly And Disposal Of The Wooden Technical Platform. Preparation Of The Ceiling Subfloor. Installation Of A New Technical Platform. Installation Of New Ceiling Insulation. Disassembly And Disposal Of Old Hatches. Installation Of New Hatches. A Detailed Description Of The Subject Of The Order (Material And Quantitative) Is Included In Annex No. 1 To This Swz, I.E. Design Documentation Prepared By The Contractor: Neksis Sp. Z O. O. With Headquarters: Ul. Piaskowa 44 Jastkowice, 37-403 Pysznica, Which Consists Of: - Architectural And Construction Design - Technical Design - Technical Specification For The Execution And Acceptance Of Construction Works (Stwiorb) - Bill Of Quantities - Decision On The Construction Permit The Bill Of Quantities Attached To The Above-Mentioned Dokumentacji Ma Charakter Pomocniczy I Informacyjny. Błędy Przedmiaru Robót Nie Mogą Być Powodem Roszczeń Wykonawcy Względem Zamawiającego.2.The Ordering Party Informs That The Contractor Should Take Into Account The Following Circumstances When Preparing The Offer And Subsequent Performance Of The Works: 2.1.The Ordering Party Requires That The Transport Of Materials And Waste During Disassembly And Assembly Take Place Without Disturbing The Operation Of The Facility, Indicating As The Route For Transporting Materials A Route Through Roof Hatches To The Roof And Then Through The Roof Outside Towards The West (The Parking Lot Square On The Side Of The Oak), The Ordering Party Will Provide The Designated Square, In Consultation With The Contractor, Free Of Charge.2.2.Pedestrian Routes On The Roof Covered With A Membrane, Along Which The Transport Of Materials And Pedestrians Will Take Place, Should Be Protected Against Damage Using Double Thick Foil And Osb Boards Or System Platforms, Or Other Protection Proposed By The Contractor, Agreed With The Supervision Inspector And The Ordering Party.2.3.Existing Fire Detectors. Oraz Lampy Ewakuacyjne Zamontowane Na Dachu Zabezpieczyć Fizycznie Przed Pyleniem I Uszkodzeniem Podczas Prac.2.4.Ciąg Technologiczny Transportu Materiałów I Odpadów, Organizacja I Sprzęt Po Stronie Wykonawcy.2.5.It Is Required That The Waste And Material Storage Area Designated In Consultation With The Ordering Party Remains Fenced And Marked. Openwork Fencing Is Not Allowed. The Temporary Fence Of The Work Area Should Be Made Full, Opaque, In A Way That Prevents Access By Unauthorized Persons And Limits The Spread Of Dust And Pollution Outside The Work Zone.2.6.Only Employees Without Material Will Be Able To Move Through The Court Building Along The Designated Route To The Work Site In Consultation With The Employers Representa