Tenders Are Invited For Works To Reform The Municipal Medical Office. The Purpose Of The Action Is To Renovate And Functionally Adapt The Current Office Space, In Accordance With The Technical Project Drawn Up By The Architect Xavier Cerqueda Ribó. - Tender Submission Deadline: 20 Calendar Days, Counting From The Day After The Publication Of The Announcement On The Contractors Profile. - Basic Tender Budget: €212,667.47, Vat Included. Taxable Base: €175,758.24 Vat 21%: €36,909.23 The Contract Is Divided Into Two Lots:- Lot 1 — Civil Work Taxable Base: €103,180.99 Vat 21%: €21,668.01 Total Vat Included: €124,849.00 - Lot 2 — Installations And Flooring Taxable Base: €72,577.25 Vat 21%: €15,241.22 Total Vat Included: €87,818.47 The Bidding Companies Can Submit An Offer For One Or Both Lots. Each Lot Will Be Subject To Independent Assessment And Adjudication, Without Prejudice To The Necessary Coordination To Guarantee The Correct Overall Execution Of The Works.- Overall Execution Pe

Works To Reform The Municipal Medical Office. The Purpose Of The Action Is To Renovate And Functionally Adapt The Current Office Space, In Accordance With The Technical Project Drawn Up By The Architect Xavier Cerqueda Ribó. - Tender Submission Deadline: 20 Calendar Days, Counting From The Day After The Publication Of The Announcement On The Contractors Profile. - Basic Tender Budget: €212,667.47, Vat Included. Taxable Base: €175,758.24 Vat 21%: €36,909.23 The Contract Is Divided Into Two Lots:- Lot 1 — Civil Work Taxable Base: €103,180.99 Vat 21%: €21,668.01 Total Vat Included: €124,849.00 - Lot 2 — Installations And Flooring Taxable Base: €72,577.25 Vat 21%: €15,241.22 Total Vat Included: €87,818.47 The Bidding Companies Can Submit An Offer For One Or Both Lots. Each Lot Will Be Subject To Independent Assessment And Adjudication, Without Prejudice To The Necessary Coordination To Guarantee The Correct Overall Execution Of The Works.- Overall Execution Period: 17 Weeks. - Duration Of Lot 1: 17 Weeks. - Duration Of Lot 2: 9 Weeks.