Tenders Are Invited For Improving The Architectural And Communication Accessibility Of The Buildings Of The Municipal Office And The Municipal-Commune Social Welfare Center In Ropczyce

1/ Part 1 - Improving The Architectural And Communication Accessibility Of The City Hall Building.1.1. The Subject Of The Order, Part I, Includes The Following Scope Of Works: A) Extension Of An Elevator Shaft With Installation Of An Elevator: On The Western Side, An Expansion Jointed Elevator Shaft, Dimensions 5.00 M X 2.80 M, Functionally Connected To The Existing Building + Installation Of A Through Elevator For The Disabled, Serving All Floors Of The Building, B) Expansion Of The Connector Between Part A And Part B Of The Municipal Office Building: Expansion Of The Connector On The Western Side With A Segment Of Dimensions 6.13 M X 4.06 M At The Level Of The First Floor, With Access To The Internal Parking Lot At Ground Level, C) Extension Of The Connector Between Part A And Part B: Extension Of The Connector Between Parts A And B Of The Municipal Office Building In Ropczyce (The Existing Part And Its Extension) By One Floor. The Designed Superstructure Will Not Be Higher Than Part B And The Angle Of The Roof Slope And The Height Of The Ridge Will Be The Same As In Part A Of The Building Of The Municipal Office In Ropczyce, D) Reconstruction Of The Building Of The Municipal Office In Ropczyce, Including: - Elimination Of Architectural Barriers For The Disabled - Installation Of A Stair Platform Overcoming The Level Difference Of 0.80 M In The Connector Of Part A With Part B, At The First Floor Level, - Elimination Of Existing Sanitary Facilities In The Segment A In The Entire Vertical And Creating A Communication Space In Their Place, Functionally Connecting The Elevator With The Existing Part A Of The Municipal Office Building In Ropczyce, - Changing The Function (Reconstruction) Of Rooms On The Ground Floor In Part A And On The First Floor In Part B Of The Building, From Office Rooms To Sanitary Facilities, - Development Of The Space In The Soul Of The Staircase In Building A By Building A Shaft With A Steel And Glass Structure, A New Room Will Be Created On Each Floor Intended For Office Equipment (Mainly Photocopiers), - Adapting The Building To The Currently Applicable Technical Conditions In The Field Of Fire Safety - Separating Fire Zones Using Fire Separation Walls With Doors Of Aluminum, Post-School Construction, - Widening Door Openings That Do Not Have The Required Width Of 0.90 M Within The Frame, - Reconstruction Of Internal Sanitary Sewage, Water Supply, Central Heating And Electrical Installations.1.2. Special Conditions For The Implementation Of The Subject Of The Order. A) The Building Of The Municipal Office Will Be An Active Facility, B) The Works Should Be Carried Out In Such A Way That The Office Can Continue To Function, C) Permanent Access To The Office Should Be Ensured For Petitioners, D) Permanent Access To Sanitary Facilities In The Facility Should Be Ensured, E) During The Work, Constant Communication Between Parts Of The Building A And B And Constant Communication Via Staircases (Patency) Should Be Ensured, F) Sup